Open · 6 days leftCorrected

Construction and installation
BKP 9 Furnishings
NPK 700 Fittings, furnishings and equipment

New building Clinic 2, phase 1, SKP 723, ceiling pendant supply units

Published in German / French. Sign in and TEXFY shows the texts in English. Sign in

Procuring office: Universitätsspital Basel
Requesting office: Healthcare Infra AG

Corrected publication

Changed according to simap: Submission deadline, Obtaining the documents, Validity of the bid

Remark of the contracting authority

Sehr geehrte Anbieter
Die Dokumente:
-022_USB_AB_ SKP723_Basisdokument_Deckenpendel
-022_USB_AB_SKP723_Werkvertrag_Enwurf_Deckenpendel
wurden inhaltlich ergänzt. Sie finden die Anpassungen grün hinterlegt.
Im Leistungsverzeichnis "-022_TMP_AL_73200_Deckenpendel_Leistungsverzeichnis022_TMP_AL_73200_Deckenpendel_Leistungsverzeichnis" wurde die Pos. 1.1.26 angepasst.
Die ergänzten Dokumente sind ab 31.10.2026 auf Simap verfügbar.
Die Änderungen sind bindend und bei der Erstellung der Angebote zwingend zu berücksichtigen.
Aufgrund der Anpassung gewährt die Bauherrschaft eine Fristverlängerung für die Offerteingabe bis zum 17.11.2026 / 15.00 Uhr.
Freundliche Grüsse
Vergabestelle NBK2

First published on 25.09.2026. The current version on simap.ch is authoritative.

At a glance

Deadline: 17.11.2026, 15:006 days left
Place: Canton BS
Type: Construction and installation
Procedure: Open procedure
Award weighting: In the documents
Eligibility: In the documents
Site visit: Not stated

Is a bid worth it?

With a free profile, TEXFY checks this tender against your services and cantons: a relevance grade from A to E and a recommendation with reasons.

Start for free

TEXFY assessment: Risks and notes

Tight deadlineNote
6 days left to submit. Plan documents, proofs and delivery now.
From «Submission deadline»
Bid languageNote
The bid must be in German.
From «Bid languages»
Publication correctedNote
The contracting authority changed details. The current version applies.
From «Correction»

2 more notes

Paper onlyGood to know
Submission by post or in person. Allow for delivery and check whether the postmark or receipt counts.
From «Submission»
No variantsGood to know
Only the requested bid counts; your own alternative solutions are not allowed.
From «Variants»

TEXFY assessment: by fixed rules, no AI. Everything else comes from the publication; in another language it is machine-translated.

Checked against simap: 10.11.2026, 18:02

AI summary

Pro

With Pro, an AI summarises this tender: services, requirements, conditions, dates and award criteria, with key figures, a timeline and the weighting, each with the literal quote from the publication.

This is how an AI summary is structured

In brief
Services
Requirements
Conditions
Dates
Award criteria

An example of the structure without content: no summary is stored for this tender yet.

What is being procured?

Scope of work

Language of the publication

Lieferung, Montage und Inbetriebnahme von Deckenpendel mit Zubehör für den Neubau Klinikum 2, am Universitätsspital Basel.

Key facts, codes and options

Type of contract: Construction and installation
Type of construction: Building construction
Construction service: Execution
Procedure: Open procedure
Trades: BKP 9 – Furnishings
NPK 700 – Fittings, furnishings and equipment
CPV: CPV 45000000 – Construction workCPV general: general code without a field
CPV 33100000 – Medical equipments
CPV 45231223 – Gas distribution ancillary work
CPV 51400000 – Installation services of medical and surgical equipment
Options: Not provided for
Variants: Not admitted
Partial offers: Not admitted

TEXFY assessment: Products, installations, quantities, technical specifications and exclusions are not structured fields of the publication. TEXFY does not analyse the free text on them: check the original text and the tender documents.

Dates

Published: 31.10.2026 (first published 25.09.2026)
Documents available: 25.09.2026 to 16.11.2026
Questions untilpast: 12.10.2026
Submission deadlinenext: 17.11.2026, 15:00
Bid valid: until 16.11.2027
Contract: 19.03.2027 to 14.09.2031
Execution: 25.06.2027 to 14.03.2031

Submission & documents

According to the simap data. We submit nothing for you.

By post or delivery in person
Universitätsspital BaselRechtsdienstKlingelbergstrasse 234031 Basel
The information in the tender and the tender documents is authoritative. Check in particular whether the postmark or receipt counts.
Source: simap data

Tender documents: Documents on simap.ch (after signing in)

Languages of the bid: German
Language of the documents: German, French
Cost of the documents: Free of charge
Questions to the contracting authority: Through an external system as stated in the tender.TEXFY sends no questions. The deadlines of the question rounds are under “Dates”.

Participation & award

In the documents according to the source: Content only in the tender documentsIn the tender documents: Suitability criteria, Award criteria, Conditions of participation, Documents to submit.

Conditions

Rules for the bid and the contract, for example whether consortia or subcontractors are allowed and how payment works.

4 conditions

Bidding consortia: Allowed
Subcontractors: Allowed
Contract extension: Not provided for
Dialogue: Not provided for

The glossary explains terms such as eligibility criteria, self-declaration or reference. To the glossary

Official source

Go to the official tender

simap project number: 44333
Publication number: 44333-02
Covered by international agreements: Yes
Notice of legal remedies: ShowHide
Gegen diese Ausschreibung kann innert 20 Tagen, von der Veröffentlichung auf www.simap.ch an gerechnet, beim Verwaltungsgericht Basel-Stadt, Bäumleingasse 1, 4051 Basel, schriftlich Beschwerde erhoben werden. Die Beschwerdeschrift muss einen Antrag, dessen Begründung sowie eine genaue Bezeichnung der Beweismittel enthalten. Die angefochtene Ausschreibung ist beizulegen.

Checked against simap: 10.11.2026, 18:02

Export

This is not an official publication. Only the data published on the platform www.simap.ch is authoritative. Dies ist keine amtliche Veröffentlichung. Massgebend sind die auf der Plattform www.simap.ch veröffentlichten Daten. Anyone who reuses this data complies with the conditions of simap.ch: terms, section 6.

More in the guide

Contract awards in Basel-Stadt: monthly reports

Report a data error

Is something on this page wrong, missing or badly translated? We check every report. We correct our own classification and translations ourselves; what simap publishes can only be changed by the contracting authority.