Start for free
All tenders
Open · 21 days left
  • Construction and installation
  • BKP 25 Sanitary installations

New construction of the Maihof I school, sports and leisure facility BKP 250

Published in German. Sign in and TEXFY shows the texts in English. Sign in

Procuring office
Gemeinde Feusisberg
Go to the official tender(simap.ch, opens in a new tab)

At a glance

Deadline
02.12.2026, 11:3021 days left
Place
Canton SZ
Type
Construction and installation
Procedure
Open procedure
Award weighting
Price 80 %Other criteria 20 %
Eligibility
2 criteria2 proofs
Site visit
Not mandatory

Is a bid worth it?

With a free profile, TEXFY checks this tender against your services and cantons: a relevance grade from A to E and a recommendation with reasons.

Start for free

TEXFY assessment: Risks and notes

2 more notes

  • Paper onlyGood to know

    Submission by post or in person. Allow for delivery and check whether the postmark or receipt counts.

    Die Angebote sind verschlossen (1-fach in Papierform, einfach digital auf USB-Stick) abzugeben. From «Submission»

  • No variantsGood to know

    Only the requested bid counts; your own alternative solutions are not allowed.

    From «Variants»

TEXFY assessment: by fixed rules, no AI. Everything else comes from the publication; in another language it is machine-translated.

Checked against simap: 10.11.2026, 18:02

What is being procured?

Scope of work

Die Gemeinde Feusisberg realisiert mit der Schul-, Sport- und Freizeitanlage Maihof in Schindellegi ein umfangreiches Bauvorhaben. Das Projekt umfasst insbesondere den Neubau einer eingeschossigen Tiefgarage mit 144 Parkplätzen sowie die darauf angeordneten Sport- und Freizeitanlagen. Weiter sind die Erweiterung des Pausenplatzareals, die Erneuerung der Laufbahn und des BeachvoIIeybaIIfeIdes, die Gestaltung des Höhenwegs, sowie die Begrünung der Anlagen und Umgestaltung der Fusswegverbindungen Bestandteil des Projekts.

Key facts, codes and options

Type of contract
Construction and installation
Type of construction
Building construction
Construction service
Execution
Procedure
Open procedure
Trades
  • BKP 25 – Sanitary installations
CPV
  • CPV 45330000 – Plumbing and sanitary works
Options
Not provided for
Variants
Not admitted
Partial offers
Not admitted

TEXFY assessment: Products, installations, quantities, technical specifications and exclusions are not structured fields of the publication. TEXFY does not analyse the free text on them: check the original text and the tender documents.

Dates

Published
20.10.2026
Documents available
20.10.2026 to 02.12.2026
Questions untilpast
30.10.2026

Fragen zur Ausschreibung sind schriftlich bis spätestens am 30.10.2026 in deutscher Sprache im simap Forum zu stellen. Die Antworten werden ebenfalls in deutscher Sprache im gleichen Forum veröffentlicht. Nach dem 30.10.2026 eintreffende Fragen werden nicht mehr beantwortet.

Submission deadlinenext
02.12.2026, 11:30
Opening of bidsnext
02.12.2026, 8835 Feusisberg, not public
Bid valid
360 days after the deadline

Das Eingabedatum ist gleichzeitig Stichtag für die Kostengrundlagen. Verzichtet der Bauherr ganz oder teilweise auf die Ausführung der Arbeiten, entstehen daraus für den Unternehmer keine Schadenersatzansprüche.

Contract
01.03.2027 to 30.11.2028
Execution
01.03.2027 to 30.11.2028

März 2027, bzw. innert 20 Tagen nach rechtskräftiger Arbeitsvergabe. Der Unternehmer bzw. ARGE können infolge Verzögerung des Baubeginns gegenüber der Bauherrschaft keine Mehrkosten geltend machen.

Site visit

Note of the contracting authority (date, time and place as published)

Es findet keine Begehung statt.

Special deadlines and formal requirements

Das Risiko der rechtzeitigen Zustellung liegt beim Unternehmer. Die Angebote sind verschlossen (1-fach in Papierform, einfach digital auf USB-Stick) abzugeben.

Submission & documents

According to the simap data. We submit nothing for you.

  • By post or delivery in person

    Gemeinde Feusisbergvertreten durch das BauamtDorfstrasse 388835 Feusisberg

    The information in the tender and the tender documents is authoritative. Check in particular whether the postmark or receipt counts.

    Source: simap data

Tender documents
Documents on simap.ch (after signing in)
Languages of the bid
German
Language of the documents
German
Cost of the documents
Free of charge
Questions to the contracting authority
Through the question forum on simap.ch (registration as a bidder required). Go to the official tender (simap.ch, opens in a new tab)TEXFY sends no questions. The deadlines of the question rounds are under “Dates”.

Participation & award

Weighting in percent, as published.

In the documents according to the source: Content only in the tender documentsIn the tender documents: Conditions of participation.

Abbreviations in the publication (German): EK = eligibility criterion, ZK = award criterion.

Participation & suitability

Must-have criteria: a bidder who fails one or leaves out the required proof is excluded before the bids are scored.

2 eligibility criteria

  1. EK 1

    TEXFY assessment: What this means: Experience – whether you have carried out comparable contracts, shown with references.

    Referenzen

    Evidence

    gem. Submissionsunterlagen

  2. EK 2

    Leistungsanteile

    Evidence

    gem. Submissionsunterlagen

Award criteria

How valid bids are compared: each criterion counts with its weighting, the bid with the most points wins the contract.

  1. ZK 1

    80 %Price criterion

    TEXFY assessment: What this means: Price – what your offer costs. Usually the cheapest offer gets full points, more expensive ones fewer.

    Preis

  2. ZK 2

    20 %

    TEXFY assessment: What this means: Personnel – how qualified and experienced the people carrying out the contract are, such as the project manager.

    Referenzen Schlüsselpersonen

Conditions

Rules for the bid and the contract, for example whether consortia or subcontractors are allowed and how payment works.

4 conditions
Bidding consortia
Allowed

gem. Submissionsunterlagen

Subcontractors
Allowed

gem. Submissionsunterlagen

Contract extension
Not provided for
Dialogue
Not provided for

Documents to submit

Only evidence that the publication itself names. This evidence belongs in the bid. The tender documents may ask for more.

2 pieces of evidence according to the publication
  • Suitability · EK 1

    gem. Submissionsunterlagen

  • Suitability · EK 2

    gem. Submissionsunterlagen

The glossary explains terms such as eligibility criteria, self-declaration or reference. To the glossary

Official source

Go to the official tender(simap.ch, opens in a new tab)
simap project number
46039
Publication number
46039-01
Covered by international agreements
No
Notice of legal remedies
Show

Gegen die Ausschreibung kann innert 20 Tagen seit der Publikation auf www.simap.ch beim Verwaltungsgericht des Kantons Schwyz, Postfach 2266, 6431 Schwyz, schriftlich und begründet Beschwerde eingereicht werden (Art. 52 ff. IVöB). Es gelten keine Gerichtsferien.

Checked against simap: 10.11.2026, 18:02

Export

This is not an official publication. Only the data published on the platform www.simap.ch is authoritative. Dies ist keine amtliche Veröffentlichung. Massgebend sind die auf der Plattform www.simap.ch veröffentlichten Daten. Anyone who reuses this data complies with the conditions of simap.ch: terms, section 6.

Contract awards in Schwyz: monthly reports
Report a data error

Is something on this page wrong, missing or badly translated? We check every report. We correct our own classification and translations ourselves; what simap publishes can only be changed by the contracting authority.

Kind of error

Please do not write personal data into it. If you are signed in, we store the report with your account.