Open · 21 days left

Construction and installation
BKP 259 Miscellaneous

New construction of the Maihof I school, sports and leisure facility BKP 259 I Sprinkler system

Published in German. Sign in and TEXFY shows the texts in English. Sign in

Procuring office: Gemeinde Feusisberg

At a glance

Deadline: 02.12.2026, 11:3021 days left
Place: Canton SZ
Type: Construction and installation
Procedure: Open procedure
Award weighting: Price 80 %Other criteria 20 %
Eligibility: 2 criteria 2 proofs
Site visit: Not mandatory

Is a bid worth it?

With a free profile, TEXFY checks this tender against your services and cantons: a relevance grade from A to E and a recommendation with reasons.

Start for free

TEXFY assessment: Risks and notes

Bid languageNote
The bid must be in German.
From «Bid languages»
References requiredNote
For eligibility you need comparable reference projects. Check number, age and size.
Referenzen gem. Submissionsunterlagen From «Eligibility criteria»
Price counts 80 %Note
Price makes up 80 % of the evaluation.
From «Award criteria»

2 more notes

Paper onlyGood to know
Submission by post or in person. Allow for delivery and check whether the postmark or receipt counts.
Die Angebote sind verschlossen (1-fach in Papierform, einfach digital auf USB-Stick) abzugeben. From «Submission»
No variantsGood to know
Only the requested bid counts; your own alternative solutions are not allowed.
From «Variants»

TEXFY assessment: by fixed rules, no AI. Everything else comes from the publication; in another language it is machine-translated.

Checked against simap: 10.11.2026, 18:02

AI summary

Pro

With Pro, an AI summarises this tender: services, requirements, conditions, dates and award criteria, with key figures, a timeline and the weighting, each with the literal quote from the publication.

This is how an AI summary is structured

In brief
Services
Requirements
Conditions
Dates
Award criteria

An example of the structure without content: no summary is stored for this tender yet.

What is being procured?

Scope of work

Die Gemeinde Feusisberg realisiert mit der Schul-, Sport- und Freizeitanlage Maihof in Schindellegi ein umfangreiches Bauvorhaben. Das Projekt umfasst insbesondere den Neubau einer eingeschossigen Tiefgarage mit 144 Parkplätzen sowie die darauf angeordneten Sport- und Freizeitanlagen. Weiter sind die Erweiterung des Pausenplatzareals, die Erneuerung der Laufbahn und des BeachvoIIeybaIIfeIdes, die Gestaltung des Höhenwegs, sowie die Begrünung der Anlagen und Umgestaltung der Fusswegverbindungen Bestandteil des Projekts.

Key facts, codes and options

Type of contract: Construction and installation
Type of construction: Building construction
Construction service: Execution
Procedure: Open procedure
Trades: BKP 259 – Miscellaneous
CPV: CPV 45330000 – Plumbing and sanitary works
Options: Not provided for
Variants: Not admitted
Partial offers: Not admitted

TEXFY assessment: Products, installations, quantities, technical specifications and exclusions are not structured fields of the publication. TEXFY does not analyse the free text on them: check the original text and the tender documents.

Dates

Published: 20.10.2026
Documents available: 20.10.2026 to 02.12.2026
Questions untilpast: 30.10.2026
Fragen zur Ausschreibung sind schriftlich bis spätestens am 30.10.2026 in deutscher Sprache im simap Forum zu stellen. Die Antworten werden ebenfalls in deutscher Sprache im gleichen Forum veröffentlicht. Nach dem 30.10.2026 eintreffende Fragen werden nicht mehr beantwortet.
Submission deadlinenext: 02.12.2026, 11:30
Opening of bidsnext: 02.12.2026, 8835 Feusisberg, not public
Bid valid: 360 days after the deadline
Das Eingabedatum ist gleichzeitig Stichtag für die Kostengrundlagen. Verzichtet der Bauherr ganz oder teilweise auf die Ausführung der Arbeiten, entstehen daraus für den Unternehmer keine Schadenersatzansprüche
Contract: 01.03.2027 to 30.11.2028
Execution: 01.03.2027 to 30.11.2028
März 2027, bzw. innert 30 Tagen nach rechtskräftiger Arbeitsvergabe. Der Unternehmer bzw. ARGE können infolge Verzögerung des Baubeginns gegenüber der Bauherrschaft keine Mehrkosten geltend machen

Site visit

Note of the contracting authority (date, time and place as published)

Es findet keine Begehung statt.

Special deadlines and formal requirements

Das Risiko der rechtzeitigen Zustellung liegt beim Unternehmer. Die Angebote sind verschlossen (1-fach in Papierform, einfach digital auf USB-Stick) abzugeben.

Submission & documents

According to the simap data. We submit nothing for you.

By post or delivery in person
Gemeinde Feusisbergvertreten durch das BauamtDorfstrasse 388835 Feusisberg
The information in the tender and the tender documents is authoritative. Check in particular whether the postmark or receipt counts.
Source: simap data

Tender documents: Documents on simap.ch (after signing in)

Languages of the bid: German
Language of the documents: German
Cost of the documents: Free of charge
Questions to the contracting authority: Through the question forum on simap.ch (registration as a bidder required). Go to the official tender (simap.ch, opens in a new tab)TEXFY sends no questions. The deadlines of the question rounds are under “Dates”.

Participation & award

Weighting in percent, as published.

In the documents according to the source: Content only in the tender documentsIn the tender documents: Conditions of participation.

Abbreviations in the publication (German): EK = eligibility criterion, ZK = award criterion.

Participation & suitability

Must-have criteria: a bidder who fails one or leaves out the required proof is excluded before the bids are scored.

2 eligibility criteria

EK 1
TEXFY assessment: What this means: Experience – whether you have carried out comparable contracts, shown with references.
Referenzen
Evidence
gem. Submissionsunterlagen
EK 2
Leistungsanteile
Evidence
gem. Submissionsunterlagen

Award criteria

How valid bids are compared: each criterion counts with its weighting, the bid with the most points wins the contract.

ZK 1
80 %Price criterion
TEXFY assessment: What this means: Price – what your offer costs. Usually the cheapest offer gets full points, more expensive ones fewer.
Preis
ZK 2
20 %
TEXFY assessment: What this means: Personnel – how qualified and experienced the people carrying out the contract are, such as the project manager.
Referenzen Schlüsselpersonen

Conditions

Rules for the bid and the contract, for example whether consortia or subcontractors are allowed and how payment works.

4 conditions

Bidding consortia: Allowed
gem. Submissionsunterlagen
Subcontractors: Allowed
gem. Submissionsunterlagen
Contract extension: Not provided for
Dialogue: Not provided for

Documents to submit

Only evidence that the publication itself names. This evidence belongs in the bid. The tender documents may ask for more.

2 pieces of evidence according to the publication

Suitability · EK 1
gem. Submissionsunterlagen
Suitability · EK 2
gem. Submissionsunterlagen

The glossary explains terms such as eligibility criteria, self-declaration or reference. To the glossary

Official source

Go to the official tender

simap project number: 46041
Publication number: 46041-01
Covered by international agreements: No
Notice of legal remedies: ShowHide
Gegen die Ausschreibung kann innert 20 Tagen seit der Publikation auf www.simap.ch beim Verwaltungsgericht des Kantons Schwyz, Postfach 2266, 6431 Schwyz, schriftlich und begründet Beschwerde eingereicht werden (Art. 52 ff. IVöB). Es gelten keine Gerichtsferien.

Checked against simap: 10.11.2026, 18:02

Export

This is not an official publication. Only the data published on the platform www.simap.ch is authoritative. Dies ist keine amtliche Veröffentlichung. Massgebend sind die auf der Plattform www.simap.ch veröffentlichten Daten. Anyone who reuses this data complies with the conditions of simap.ch: terms, section 6.

More in the guide

Contract awards in Schwyz: monthly reports

Report a data error

Is something on this page wrong, missing or badly translated? We check every report. We correct our own classification and translations ourselves; what simap publishes can only be changed by the contracting authority.